{"id":"court_ctb_728_1","court":"CTB","case_no":"22-50073","doc_number":728,"sub_number":1,"doc_type":"EXHIBIT","filed_date":"2022-08-11","title":"EXHIBIT A Bridgeport Boatworks 731 Seaview Ave Bridgeport, CT 06607 United States (860) 536-9651","summary_zh":null,"summary_en":null,"body_en":"# **EXHIBIT A**\n\nBridgeport Boatworks 731 Seaview Ave Bridgeport, CT 06607 United States (860) 536-9651\n\n\n\n# Estimate\n\nLADY MAY - Valve Service Estimate\n\nID: 6200\n\n#### Contact Contact\n\n#### Vessel Vessel\n\nLloyd Benard captain@yachtladymay.com 1 3057994799\n\nLady May Dimensions: 151 ' x 32 ' x 7 ' Make: Feadship Weight: 0\n\n### Estimate Comments\n\nThis is the budgetary estimate to service (26) valves. This estimate does not include any valve replacement or repair due to current electrolysis. This estimate does not include any equipment to load heavy parts to and from the vessel. This estimate does not include CT Sales Tax.\n\nA \\$80,000 deposit is requested to secure estimated labor.\n\n## Service (26) Thru-Hull Valves Service (26) Thru-Hull Valves \\$153,400.00 \\$153,400.00\n\nComments: Protect areas leading to and surrounding valves. Remove & reinstall interferences. Remove valves, some valves have corroded bolts that will need to be cut. Clean, blast and paint valves. Package and ship out to LR test site for certification. This estimate does not include LR Testing Cost.\n\n| Labor | | Rate Rate | Qty Qty | Total Total |\n|-------|---------------------------------------------------------------------------------------------------|--------------------------|---------|----------------|\n| | Subcontractor Labor BB | \\$113,750.00 Flat
Fee | 1 | \\$113,750.00 N |\n| | Subcontractor Labor BB
Comments:
Comments: Shipping of Valves to LR Test Site. | \\$8,750.00 Flat Fee | 1 | \\$8,750.00 N |\n| Part | | Rate Rate | Qty Qty | Total Total |\n| | Estimated Parts BB
Comments:
Comments: Protective flooring, carpeting, paint,
new bolts. | \\$25,000.00 | 1 | \\$25,000.00 T |\n| | Charge Charge | Rate Rate | Qty Qty | Total Total |\n| | Environmental & Safety Fee BB | 4% (Parts and Labor) | 1 | \\$5,900.00 N |\n\nMolo Estimate 7/26/22, 9:50 AM Case 22-50073 Doc 728-1 Filed 08/11/22 Entered 08/11/22 14:41:45 Page 3 of 6\n\n| Labor Labor
\\$122,500.00
\\$122,500.00 | Parts Parts
\\$25,000.00
\\$25,000.00 | Charges
\\$5,900.00
\\$5,900.00 | Subtotal Subtotal
\\$153,400.00
\\$153,400.00 | Tax Tax
\\$1,587.50
\\$1,587.50 | Total Total
\\$154,987.50
\\$154,987.50 | | |\n|----------------------------------------------------------------------------|-------------------------------------------------------------------------|-------------------------------------|--------------------------------------------------------------------------------------------------------------------|-------------------------------------|---------------------------------------------|--|--|\n| Terms and Conditions
Terms and Conditions | | | | | | | |\n| | We are pleased to provide this Estimate for repair work on your vessel. | | | | | | |\n| | | | This Budgetary Estimate is based upon our inspection of your vessel, information that you have provided to us, and | | | | |\n| | | | our experience regarding similar vessels and work. It is possible that defective parts or other issues with | | | | |\n| | | | your vessel will be discovered after our work has begun and, for these reasons, this Estimate does not | | | | |\n| | | | include additional parts or labor that may be required after the job has begun. We will notify you of any | | | | |\n| | | | such issues if they should arise. Tax, Environental and Subcontractor charges may be additional if applicable. | | | | |\n| | | | The pricing set forth in this Estimate is based on the assumptions, exclusions and scope of work set forth | | | | |\n| herein, and is valid for fourteen (14) days from the date of the Estimate. | | | | | | | |\n| | | | Your acceptance of this Estimate is subject to the terms and conditions attached hereto as Exhibit A. | | | | |\n| | | | A deposit is required at the time of approval, with the balance and any additional charges due upon completion. | | | | |\n| | | | A payment schedule will be provided by Bridgeport Boatworks, laying out the estimated expenses for the upcoming | | | | |\n| | | | months work. This will allow the customer to budget/make payment on a monthly basis and keep account in the | | | | |\n| positive at all times. | | | | | | | |\n| | | | Should this Estimate and Terms and Conditions meet with your approval, kindly sign and return at your | | | | |\n| | | | earliest convenience. If you have any questions or concerns, please do not hesitate to contact us. | | | | |\n| Sincerely, | | | | | | | |\n| | | | Bridgeport Boatworks Representative_____________________________________________ | | | | |\n| | | | Customer Signature:__________________________________________________________ | | | | |\n| | | | | | | | |\n| | | | Printed Name:_______________________________________________________________ | | | | |\n| | | | Date:______________________________________________________________________ | | | | |\n| Notice Notice | | | | | | | |\n| | | | This Estimate is not an invoice and does not represent the final amount due or the balance on this | | | | |\n| | | | Estimate. For questions or concerns, please call Bridgeport Boatworks at (860) 536-9651. | | | | |\n| Exhibit A | | | | | | | |\n| Terms and Conditions | | | | | | | |\n| | | | 1. Applicability: These terms and conditions (\"Terms\") are the only terms which govern the services | | | | |\n\nvessel(s) (\"Vessel\") listed in the accompanying estimate (\"Estimate\"). The Terms and Estimate are collectively referred to herein as the \"Agreement.\" These Terms shall prevail over any prior agreements or discussions between Bridgeport Boatworks and the Owner. Owner will be deemed to have accepted these Terms upon Bridgeport Boatworks' commencement of performance of the Services or Owner's return of the signed Agreement, whichever is earlier.\n\n2. Compensation: In consideration of the performance by Bridgeport Boatworks of the Services, Owner agrees to pay Bridgeport Boatworks the fee set forth in the Estimate/Invoice (or the portion earned) upon receipt of submission of Bridgeport Boatworks' invoice or as otherwise set forth in the Agreement. In addition, Owner shall reimburse Bridgeport Boatworks for reasonable expenses incurred in performance of the Services, including but not limited to travel expenses, storage charges, shipping charges, and other reasonable expenses incurred in Bridgeport Boatworks' performance of the Services. Owner shall pay such reimbursable expenses upon receipt following Owner's receipt of an invoice containing such expenses. Any amounts due to Bridgeport Boatworks from Owner under this Agreement shall, after a thirty (30) day grace period, bear interest from the due date at the maximum rate allowed by applicable law.\n\n3. Change Requests: Owner may request a change to any portion of the Services at any time by submitting such request in writing to Bridgeport Boatworks (\"Change Request\"). Within a reasonable time after receipt of a Change Request from Owner, Bridgeport Boatworks shall evaluate the impact of the Change Request and provide Owner with a written statement setting forth its estimate of the cost of the change. Within a reasonable time after receipt of a Change Request from Bridgeport Boatworks, Owner shall provide a written acceptance or rejection of the Change Request. Bridgeport Boatworks' fee for the Services shall be adjusted to the extent of any increase in Services, at a fixed amount as agreed by the parties, or if the parties do not agree to a fixed amount, on a time and materials (T&M) basis at the rates set forth herin, or if no rates are set forth, at rates agreed by the parties. Bridgeport Boatworks shall not be required to proceed with a change in services absent agreement by the parties in writing.\n\n4. Warranty: Bridgeport Boatworks warrants that the Services shall be performed using personnel of required skill, experience and qualifications in a professional and workmanlike manner. Other than as set forth herein, Bridgeport Boatworks makes no warranties regarding workmanship or materials, either express or implied, including any implied warranty or merchantability, fitness for a particular purpose or seaworthiness.\n\n5. Fees and Costs: Owner shall reimburse Bridgeport Boatworks for all costs incurred in collecting any late payments, including, without limitation, attorneys' fees. In addition to all other remedies available under this Agreement or at law (which Bridgeport Boatworks does not waive by the exercise of any rights hereunder), Bridgeport Boatworks shall be entitled to suspend the delivery of any goods or performance of any services hereunder if the Owner fails to pay any amounts when due hereunder.\n\n6. Liability of Bridgeport Boatworks: Bridgeport Boatworks shall have no liability for any matters arising out of or related to this Agreement except to the extent caused by the sole negligence of Bridgeport Boatworks or those for whom it is directly responsible. In no event shall Bridgeport Boatworks' liability for any matters arising out of or related to this Agreement exceed the fee paid to Bridgeport Boatworks under this Agreement. No principal, partner, member, director, officer, agent, servant, employee, or consultant of Bridgeport Boatworks shall have any personal liability relating to the subject matter of this Agreement.\n\n7. Insurance: Owner shall at all times maintain adequate and customary insurance covering the Vessel for the duration of the Services, including while the Vessel is in the custody and/or control of Bridgeport Boatworks. Owner and Bridgeport Boatworks each hereby waive their entire right of recovery against the other for injury, loss, or damage to the extent covered by insurance proceeds received by the damaged party. All policies required hereunder shall provide that the respective carrier(s) waives all rights of subrogation with respect to losses payable under such policies.\n\n8. Termination: Bridgeport Boatworks shall have the right to terminate this Agreement upon seven (7) days' written notice in the event that Owner is in material breach of its obligations hereunder. In the event the Agreement is terminated for any reason prior to the completion of the Services, then, in addition to the reimbursable expenses detailed herein, Owner shall pay to Bridgeport Boatworks the balance of the remaining fee as of the date of termination, representing payment for demobilization costs, opportunity costs, and anticipated lost profit. Bridgeport Boatworks' exercise of its rights under this section shall not in any way limit or abridge other remedies available to it under the Agreement or applicable law, including any lien rights with respect to the Vessel.\n\n9. Force Majeure: Bridgeport Boatworks shall not be liable or responsible to the Owner, nor be deemed to have defaulted or breached this Agreement, for any failure or delay in fulfilling or performing any term of this Agreement when and to the extent such failure or delay is caused by or results from acts or circumstances beyond the reasonable control of Bridgeport Boatworks including, without limitation, acts of God, flood, fire, earthquake, explosion, governmental actions, war, terrorist threats or acts, riot, or other civil unrest, public emergency, epidemics or pandemics, lockouts, strikes or other labor disputes, or restraints or delays affecting carriers or inability or delay in obtaining supplies of adequate or suitable materials, materials or telecommunication breakdown or power outage.\n\n10. General Provisions:\n\na. Owner hereby grants Bridgeport Boatworks, its agents and employees, permission to operate the Vessel for the purpose of testing and/or inspection.\n\nb. Owner shall remove all articles of personal property, gear, or other appurtenances not necessary for the performance of the Services from the Vessel prior to delivery of the Vessel to Bridgeport Boatworks. Bridgeport Boatworks shall not be responsible for damage to or loss of any such articles of personal property, gear, or other appurtenances left aboard the Vessel, due to fire, theft, pilferage, or otherwise. Delivery of the Vessel does not constitute a bailment of any articles of personal property, gear, or other appurtenances left on the Vessel which are not\n\nnecessary for the performance of the Services.\n\nc. This Agreement constitutes the entire agreement between the parties hereto regarding the subject matter hereof, and supersedes all prior agreements, whether written or oral. d. No change, modification, or amendment shall be made to this Agreement unless set forth in writing and signed by the parties hereto. e. All express representations, warranties, indemnifications, and limits of liability included in this\n\nAgreement will survive its completion or termination for any reason. If any provision of this Agreement shall be held invalid, illegal or unenforceable by a court of competent jurisdiction, the validity, legality and enforceability of the remaining provisions shall in no way be affected or impaired thereby. The remaining provisions shall remain in full force and effect, as if the unenforceable provision had been deleted. The parties agree to replace any omitted provision with a valid provision that comes as close as possible to the intent of the omitted provision. f. This Agreement shall be governed by and construed under the laws of the state in which the Services are performed, without regard to its conflicts of laws principles. g. Bridgeport Boatworks and Owner will first attempt to resolve disputes or disagreements through discussions between their respective representatives, who shall meet upon the request of either party as soon as conveniently possible to attempt to resolve such dispute or disagreement. If after meeting, the representatives determine that the dispute or disagreement cannot be resolved on terms satisfactory to both parties, the parties shall submit the dispute or disagreement to non-binding mediation. The mediation shall be conducted by a mutually agreeable impartial mediator, or if the parties cannot so agree, a mediator designated by the American Arbitration Association (\"AAA\"). If a dispute has not been resolved in accordance with the procedures set forth above, such disputes shall be decided by arbitration in accordance with the applicable AAA rules then in effect, unless the parties mutually agree otherwise. The award of the arbitrator(s) shall be final and binding upon the parties without the right of appeal to the courts. Judgment may be entered upon it in accordance with applicable law by any court having jurisdiction thereof.\n\n#### Notice\n\nThis estimate is not an invoice and does not represent the final amount due or the balance on this estimate.\n\nFor questions or concerns, please call Bridgeport Boatworks at (860) 536-9651.","body_zh":"证据 A\n\nBridgeport Boatworks（布里奇波特船厂） 731 Seaview Ave Bridgeport, CT 06607 United States (860) 536-9651\n估算单\n\nLADY MAY（五月女士号）- 阀门检修估算\n\n编号：6200\n联系人 联系人\n船只 船只\n\nLloyd Benard（劳埃德·贝纳德） captain@yachtladymay.com 1 3057994799\n\nLady May 尺寸：151 英尺 x 32 英尺 x 7 英尺 制造商：Feadship（斐帝星） 重量：0\n估算备注\n\n此项为检修（26）个阀门的预算估算。本估算不包含因现有电解腐蚀而导致的任何阀门更换或修理。本估算不包含用于将重型部件装载至船只及从船只卸下的任何设备。本估算不包含康涅狄格州（CT）销售税。\n\n要求支付 $80,000 的定金以锁定估算的人工工时。\n检修（26）个穿舷阀门 检修（26）个穿舷阀门 $153,400.00 $153,400.00\n\n备注：保护通往阀门及阀门周边的区域。拆卸并重新安装干涉部件。拆卸阀门，部分阀门螺栓已锈蚀，需进行切割。清理、喷砂并喷涂阀门。包装并运送至劳氏船级社（LR）测试地点进行认证。本估算不包含劳氏船级社测试费用。\n\n人工 费率 费率 数量 数量 总计 总计\n\n分包商人工 BB $113,750.00 固定\n费用 1 $113,750.00 N\n分包商人工 BB\n备注：\n备注：将阀门运送至劳氏船级社测试地点。 $8,750.00 固定费用 1 $8,750.00 N\n配件 费率 费率 数量 数量 总计 总计\n预估配件 BB\n备注：\n备注：保护性铺地、地毯、油漆、\n新螺栓。 $25,000.00 1 $25,000.00 T\n收费 收费 费率 费率 数量 数量 总计 总计\n环境与安全费 BB 4%（配件和人工） 1 $5,900.00 N\n\nMolo 估算 7/26/22, 9:50 AM 案号 22-50073 文件 728-1 提交于 08/11/22 录入于 08/11/22 14:41:45 第 3 页，共 6 页\n\n人工 人工\n$122,500.00\n$122,500.00 配件 配件\n$25,000.00\n$25,000.00 费用\n$5,900.00\n$5,900.00 小计 小计\n$153,400.00\n$153,400.00 税费 税费\n$1,587.50\n$1,587.50 总计 总计\n$154,987.50\n$154,987.50\n\n条款与条件\n条款与条件\n我们很高兴为您提供关于贵方船只维修工程的本份估算单。\n本预算估算是基于我们对贵方船只的检查、贵方向我们提供的信息，以及\n我们处理类似船只和工程的经验所作出。在我们的工作开始后，可能会发现贵方船只存在缺陷配件或其他问题，\n鉴于这些原因，本估算不包含工作开始后可能需要的额外配件或人工。\n如果出现此类问题，我们将通知贵方。税费、环境费和分包商费用（如适用）可能需额外收取。\n本估算中所列价格基于本文所述的假设、除外条款和工作范围，\n且自估算之日起十四（14）天内有效。\n贵方对本估算的接受受制于随附作为证据 A 的条款与条件。\n批准时需支付定金，余款及任何额外费用在完工时付清。\nBridgeport Boatworks 将提供一份付款进度表，列明接下来数月工作的预计支出。\n这将便于客户按月进行预算/付款，并使账户随时保持盈余状态。\n如果本估算及条款与条件获得贵方认可，请尽早签署并回传。如果您有任何问题或疑虑，请随时联系我们。\n此致，\nBridgeport Boatworks 代表_____________________________________________\n客户签名：__________________________________________________________\n\n印刷体姓名：_______________________________________________________________\n日期：______________________________________________________________________\n通知 通知\n本估算不是发票，不代表最终应付金额或本估算单上的余额。如有疑问或疑虑，请致电 Bridgeport Boatworks，电话 (860) 536-9651。\n证据 A\n条款与条件\n1. 适用性：这些条款与条件（“条款”）是管辖随附估算单（“估算”）所列船只（“船只”）服务的唯一条款。条款与估算在本文中统称为“协议”。这些条款应优先于 Bridgeport Boatworks 与船东之间的任何先前协议或讨论。一旦 Bridgeport Boatworks 开始履行服务，或船东回传签署的协议（以较早发生者为准），即视为船东已接受这些条款。\n\n2. 报酬：作为 Bridgeport Boatworks 履行服务的对价，船东同意在收到 Bridgeport Boatworks 提交的发票后或按照协议另行规定的方式，向 Bridgeport Boatworks 支付估算/发票中所列的费用（或已赚取的部分）。此外，船东应补偿 Bridgeport Boatworks 在履行服务过程中产生的合理费用，包括但不限于差旅费、仓储费、运费以及 Bridgeport Boatworks 在履行服务过程中产生的其他合理费用。船东应在收到包含此类费用的发票后，凭发票支付此类可补偿费用。船东根据本协议应付给 Bridgeport Boatworks 的任何款项，在三十（30）天宽限期过后，应自到期日起按适用法律允许的最高利率计息。\n\n3. 变更请求：船东可随时通过向 Bridgeport Boatworks 提交书面请求，要求对服务的任何部分进行变更（“变更请求”）。在收到船东的变更请求后的合理时间内，Bridgeport Boatworks 应评估该变更请求的影响，并向船东提供一份书面声明，列出其对变更费用的估算。在收到 Bridgeport Boatworks 的变更请求后的合理时间内，船东应提供书面的接受或拒绝该变更请求的意见。Bridgeport Boatworks 的服务费用应根据服务的增加程度进行调整，调整方式为双方约定的固定金额，或者如果双方未就固定金额达成一致，则按照本文所列费率按工料计价（T&M）方式计算，如果未列明费率，则按双方约定的费率计算。在双方未达成书面协议的情况下，Bridgeport Boatworks 不得被要求继续进行服务变更。\n\n4. 保证：Bridgeport Boatworks 保证应由具备所需技能、经验和资质的人员以专业和熟练的方式履行服务。除本文另有规定外，Bridgeport Boatworks 不对工艺或材料作出任何明示或默示的保证，包括对适销性、特定用途适用性或适航性的任何默示保证。\n\n5. 费用与成本：船东应补偿 Bridgeport Boatworks 为催收任何逾期款项而产生的所有费用，包括但不限于律师费。除本协议项下或法律上可获得的所有其他救济（Bridgeport Boatworks 行使本协议项下的任何权利并不放弃上述救济）外，如果船东未能在到期时支付本协议项下的任何款项，Bridgeport Boatworks 有权暂停交付本协议项下的任何货物或暂停履行本协议项下的任何服务。\n\n6. Bridgeport Boatworks 的责任：Bridgeport Boatworks 对由本协议引起或与本协议相关的任何事项不承担任何责任，除非该等事项是由于 Bridgeport Boatworks 或其直接负责的人员的单独过失所致。在任何情况下，Bridgeport Boatworks 对由本协议引起或与本协议相关的任何事项所承担的责任，均不得超过根据本协议已支付给 Bridgeport Boatworks 的费用。Bridgeport Boatworks 的任何负责人、合伙人、成员、董事、高级职员、代理人、受雇人、雇员或顾问均不对与本协议标的相关的任何事项承担任何个人责任。\n\n7. 保险：在服务期间（包括船只处于 Bridgeport Boatworks 的保管和/或控制期间），船东应始终对船只维持足额且符合惯例的保险。船东与 Bridgeport Boatworks 特此各自向对方放弃就人身伤害、损失或损害索赔的全部追偿权，但以受损方收到保险赔偿金的限额为限。本协议项下要求的所有保单均应规定，各承保人放弃就根据此类保单应付的损失所享有的所有代位求偿权。\n\n8. 终止：如果船东实质性违反其在本协议项下的义务，Bridgeport Boatworks 有权在提前七（7）天发出书面通知后终止本协议。如果本协议在服务完成前因任何原因终止，则除本文详述的可补偿费用外，船东应向 Bridgeport Boatworks 支付截至终止之日的剩余费用余额，作为对复员撤场成本、机会成本以及预期利润损失的赔偿。Bridgeport Boatworks 行使其在本条项下的权利，不应以任何方式限制或削减其根据本协议或适用法律享有的其他救济，包括关于船只的任何留置权。\n\n9. 不可抗力：对于因超出 Bridgeport Boatworks 合理控制范围的行为或情况导致或引起的未能履行或延迟履行本协议任何条款的情况，Bridgeport Boatworks 不对船东承担责任或义务，也不应被视为违约或违反本协议，这些行为或情况包括但不限于：天灾、洪水、火灾、地震、爆炸、政府行为、战争、恐怖主义威胁或行为、暴乱或其他内乱、公共紧急状态、流行病或大流行病、停工、罢工或其他劳资纠纷，或影响承运人的限制或延误，或无法获得或延误获得充足或合适材料的供应、材料或电信故障或停电。\n\n10. 一般条款：\n\na. 船东特此授予 Bridgeport Boatworks 及其代理人和雇员为测试和/或检查目的操作船只的许可。\n\nb. 船东应在将船只交付给 Bridgeport Boatworks 之前，从船只上移走所有非履行服务所必需的个人财产物品、用具或其他属具。对于因火灾、盗窃、偷盗或其他原因留在船上的任何此类个人财产物品、用具或其他属具的损坏或丢失，Bridgeport Boatworks 概不负责。船只的交付不构成对留在船上且非\n\n履行服务所必需的任何个人财产物品、用具或其他属具的寄托。\n\nc. 本协议构成双方就本协议标的达成的全部协议，并取代所有先前的口头或书面协议。 d. 除非以书面形式作出并由本协议双方签署，否则不得对本协议进行任何更改、修改或修正。 e. 本协议中包含的所有明示陈述、保证、赔偿和责任限制\n\n本协议在因任何原因完成或终止后继续有效。若本协议的任何条款被具有管辖权的法院认定为无效、违法或不可执行，其余条款的有效性、合法性和可执行性绝不应因此受到任何影响或损害。其余条款应保持完全有效，犹如该不可执行的条款已被删除一样。双方同意以尽可能接近该被省略条款意图的有效条款替换任何被省略的条款。f. 本协议应受履行服务所在州的法律管辖并按其解释，不考虑其法律冲突原则。g. Bridgeport Boatworks（布里奇波特船厂）与所有权人将首先尝试通过各自代表之间的讨论来解决争议或分歧，代表应在任一方提出请求后在双方均方便的情况下尽快会面，以尝试解决此类争议或分歧。若在会面后，代表们认定无法以双方均满意的条件解决该争议或分歧，双方应将争议或分歧提交不具约束力的调解。调解应由双方均同意的中立调解员主持；若双方无法达成一致，则由 American Arbitration Association（美国仲裁协会，简称「AAA」）指定的调解员主持。若争议未能按照上述程序解决，除双方另有一致同意外，此类争议应根据当时有效的适用 AAA 规则通过仲裁裁决。仲裁员的裁决应为终局裁决，对双方均具有约束力，且无权向法院提起上诉。任何具有管辖权的法院均可根据适用法律依据该裁决作出判决。\n\n通知\n\n本估价单不是发票，不代表最终应付金额或本估价单上的余额。\n\n如有疑问或疑虑，请致电 Bridgeport Boatworks，电话：(860) 536-9651。","key_entities":["Je","CIPA"],"ecf_references":[],"word_count":2337,"status":"published","published_at":"2022-08-11 00:00:00","created_at":"2022-08-11","updated_at":"2026-08-23 13:48:34"}