{"id":"court_ctb_728_10","court":"CTB","case_no":"22-50073","doc_number":728,"sub_number":10,"doc_type":"EXHIBIT","filed_date":null,"title":"EXHIBIT J Bridgeport Boatworks 731 SeaviewAve Bridgeport,CT06607 United States (860) 536-9651","summary_zh":null,"summary_en":null,"body_en":"# **EXHIBIT J**\n\nBridgeport Boatworks 731 SeaviewAve Bridgeport,CT06607 United States (860) 536-9651\n\n\n\nBilge Board Replacement 2022 **ID:** 6234\n\n| Contact
Lloyd Benard
captain@yachtladymay.com
1 3057994799
1.
Bilge
Board
Replacement | | | Vessel
Lady May
Dimensions: 151 ' x 32 ' x 7 '
Make: Feadship
Weight: 0
\\$2,280.76 | | | |\n|--------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------|-----------------|--------------------|---------------------------------------------------------------------------------------------------|---------------|---------------------|--|\n| Comments: 1. Template Existing Starboard Board
2. Bevel all Edges
3. Cut out Holes for lift points and bevel edge | | | | | | |\n| Labor | | | Rate | Qty | Total | |\n| Subcontractor Labor BB
Comments: 1. Template Existing Starboard Board
2. Bevel all Edges
3. Cut out Holes for lift points and bevel edges
Lead Time 2 Weeks
**Color may differ slightly from original Color** | | | \\$2,193.04 Flat Fee | 1 | \\$2,193.04 N | |\n| Charge | | | Rate | Qty | Total | |\n| Environmental & Safety Fee BB | | | 4% (Parts and Labor) | 1 | \\$87.72 N | |\n| Labor
\\$2,193.04 | Parts
\\$0.00 | Charges
\\$87.72 | Subtotal
\\$2,280.76 | Tax
\\$0.00 | Total
\\$2,280.76 | |\n| Terms and Conditions
We are pleased to provide this Estimate for repair work on your vessel.
This BudgetaryEstimate is based upon our inspection of your vessel, information that you have provided to us, and
our experience regarding similar vessels and work. It is possible that defective parts or other issues with
your vessel will be discovered after our work has begun and, for these reasons, this Estimate does not
include additional parts or labor that maybe required after the job has begun. We will notifyyou of any
such issues if theyshould arise. Tax, Environental and Subcontractor charges maybe additional if applicable. | | | | | | |\n| The pricing set forth in this Estimate is based on the assumptions, exclusions and scope ofwork set forth
herein, and is valid for fourteen (14) days from the date of the Estimate. | | | | | | |\n| Your acceptance of this Estimate is subject to the terms and conditions attached hereto as Exhibit A.
A50%deposit of the Estimate total is required at the time of approval,with the balance and anyadditional
charges due upon completion. | | | | | | |\n\nShould this Estimate and Terms and Conditions meetwith your approval, kindlysign and return at your earliest convenience. If you have anyquestions or concerns, please do not hesitate to contact us.\n\nBridgeport Boatworks Representative\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\n\nCustomer Signatur\n\nPrinted Nam\n\nDat\n\n## **Notice**\n\nThis Estimate is not an invoice and does not represent the final amount due or the balance on this Estimate. For questions or concerns, please call Bridgeport Boatworks at (860) 536-9651.\n\n### Exhibit A\n\nTerms and Conditions\n\n1. Applicability: These terms and conditions (\"Terms\") are the onlyterms which govern the services (\"Services\") to be provided byBridgeport Boatworks to the owner (\"Owner\") of the vessel(s) (\"Vessel\") listed in the accompanying estimate (\"Estimate\"). The Terms and Estimate are collectivelyreferred to herein as the \"Agreement.\" These Terms shall prevail over anyprior agreements or discussions between Bridgeport Boatworks and theOwner.Owner will be deemed to have accepted these Terms upon Bridgeport Boatworks' commencement of performance of the Services orOwner's return of the signed Agreement,whichever is earlier.\n\n2.Compensation: In consideration of the performance byBridgeport Boatworks of the Services,Owner agrees to payBridgeport Boatworks the fee set forth in the Estimate/Invoice (or the portion earned) upon receipt of submission of Bridgeport Boatworks' invoice or as otherwise set forth in the Agreement. In addition,Owner shall reimburse Bridgeport Boatworks for reasonable expenses incurred in performance of the Services, including but not limited to travel expenses, storage charges, shipping charges, and other reasonable expenses incurred in Bridgeport Boatworks' performance of the Services.Owner shall paysuch reimbursable expenses upon receipt followingOwner's receipt of an invoice containing such expenses. Anyamounts due to Bridgeport Boatworks from Owner under this Agreement shall, after a thirty(30) daygrace period, bear interest from the due date at the maximum rate allowed byapplicable law.\n\n3.Change Requests:Owner mayrequest a change to anyportion of the Services at anytime by submitting such request in writing to Bridgeport Boatworks (\"Change Request\"). Within a reasonable time after receipt of a Change Request from Owner, Bridgeport Boatworks shall evaluate the impact of the Change Request and provideOwner with a written statement setting forth its estimate of the cost of the change. Within a reasonable time after receipt of a Change Request from Bridgeport Boatworks,Owner shall provide a written acceptance or rejection of the Change Request. Bridgeport Boatworks' fee for the Services shall be adjusted to the extent of anyincrease in Services, at a fixed amount as agreed bythe parties, or if the parties do not agree to a fixed amount, on a time and\n\nmaterials (T&M) basis at the rates set forth herin, or if no rates are set forth, at rates agreed by the parties. Bridgeport Boatworks shall not be required to proceed with a change in services absent agreement bythe parties in writing.\n\n4. Warranty: Bridgeport Boatworks warrants that the Services shall be performed using personnel of required skill, experience and qualifications in a professional and workmanlike manner.Other than as set forth herein, Bridgeport Boatworks makes no warranties regarding workmanship or materials, either express or implied, including anyimplied warrantyor merchantability, fitness for a particular purpose or seaworthiness.\n\n5. Fees and Costs:Owner shall reimburse Bridgeport Boatworks for all costs incurred in collecting any late payments, including,without limitation, attorneys' fees. In addition to all other remedies available under this Agreement or at law(which Bridgeport Boatworks does notwaive bythe exercise of anyrights hereunder), Bridgeport Boatworks shall be entitled to suspend the deliveryof anygoods or performance of anyservices hereunder if theOwner fails to payanyamounts when due hereunder.\n\n6. Liabilityof Bridgeport Boatworks: Bridgeport Boatworks shall have no liabilityfor anymatters arising out of or related to this Agreement except to the extent caused bythe sole negligence of Bridgeport Boatworks or those for whom it is directlyresponsible. In no event shall Bridgeport Boatworks' liabilityfor anymatters arising out of or related to this Agreement exceed the fee paid to Bridgeport Boatworks under this Agreement.No principal, partner, member, director, officer, agent, servant, employee, or consultant of Bridgeport Boatworks shall have anypersonal liabilityrelating to the subject matter of this Agreement.\n\n7. Insurance:Owner shall at all times maintain adequate and customaryinsurance covering the Vessel for the duration of the Services, including while the Vessel is in the custodyand/or control of Bridgeport Boatworks.Owner and Bridgeport Boatworks each herebywaive their entire right of recoveryagainst the other for injury, loss, or damage to the extent covered byinsurance proceeds received bythe damaged party. All policies required hereunder shall provide that the respective carrier(s) waives all rights of subrogation with respect to losses payable under such policies.\n\n8. Termination: Bridgeport Boatworks shall have the right to terminate this Agreement upon seven (7) days' written notice in the event thatOwner is in material breach of its obligations hereunder. In the event the Agreement is terminated for anyreason prior to the completion of the Services, then, in addition to the reimbursable expenses detailed herein,Owner shall payto Bridgeport Boatworks the balance of the remaining fee as of the date of termination, representing payment for demobilization costs, opportunitycosts, and anticipated lost profit. Bridgeport Boatworks' exercise of its rights under this section shall not in anywaylimit or abridge other remedies available to it under the Agreement or applicable law, including anylien rights with respect to the Vessel.\n\n9. Force Majeure: Bridgeport Boatworks shall not be liable or responsible to theOwner, nor be deemed to have defaulted or breached this Agreement, for anyfailure or delayin fulfilling or performing any term of this Agreementwhen and to the extent such failure or delayis caused byor results from acts or circumstances beyond the reasonable control of Bridgeport Boatworks including,without\n\nlimitation, acts ofGod, flood, fire, earthquake, explosion, governmental actions,war, terrorist threats or acts, riot, or other civil unrest, public emergency, epidemics or pandemics, lockouts, strikes or other labor disputes, or restraints or delays affecting carriers or inabilityor delayin obtaining supplies other labor disputes, or restraints or delays affecting carriers or inabilityor delayin obtaining supplies\n\nof adequate or suitable materials, materials or telecommunication breakdown or power outage.\n\n10.General Provisions:\n\na. Owner herebygrants Bridgeport Boatworks, its agents and employees, permission to operate the Vessel for the purpose of testing and/or inspection.\n\nb. Owner shall remove all articles of personal property, gear, or other appurtenances not necessary for the performance of the Services from the Vessel prior to deliveryof the Vessel to\n\nBridgeport Boatworks. Bridgeport Boatworks shall not be responsible for damage to or loss of anysuch articles of personal property, gear, or other appurtenances left aboard the Vessel, due to fire, theft, pilferage, or otherwise.Deliveryof the Vessel does not constitute a bailment of anyarticles of personal property, gear, or other appurtenances left on the Vessel which are not necessaryfor the performance of the Services.\n\nc. This Agreement constitutes the entire agreement between the parties hereto regarding the subject matter hereof, and supersedes all prior agreements,whether written or oral.\n\nd.No change, modification, or amendment shall be made to this Agreement unless set forth in writing and signed bythe parties hereto.\n\ne. All express representations,warranties, indemnifications, and limits of liabilityincluded in this Agreementwill survive its completion or termination for anyreason. If anyprovision of this Agreement shall be held invalid, illegal or unenforceable bya court of competent jurisdiction, the validity, legalityand enforceabilityof the remaining provisions shall in no waybe affected or impaired thereby. The remaining provisions shall remain in full force and effect, as if the unenforceable provision had been deleted. The parties agree to replace anyomitted provision with a valid provision that comes as close as possible to the intent of the omitted provision. f. This Agreement shall be governed byand construed under the laws of the state in which the\n\nServices are performed,without regard to its conflicts of laws principles.\n\ng. Bridgeport Boatworks andOwner will first attempt to resolve disputes or disagreements through discussions between their respective representatives,who shall meet upon the request of either partyas soon as convenientlypossible to attempt to resolve such dispute or disagreement. If after meeting, the representatives determine that the dispute or disagreement cannot be resolved on terms satisfactoryto both parties, the parties shall submit the dispute or disagreement to non-binding mediation. The mediation shall be conducted bya mutually agreeable impartial mediator, or if the parties cannot so agree, a mediator designated bythe American Arbitration Association (\"AAA\"). If a dispute has not been resolved in accordance with the procedures set forth above, such disputes shall be decided byarbitration in accordance with the applicable AAArules then in effect, unless the parties mutuallyagree otherwise. The award of the arbitrator(s) shall be final and binding upon the parties without the right of appeal to the courts. Judgment maybe entered upon it in accordance with applicable lawbyanycourt having jurisdiction thereof.\n\n# **Notice**\n\nThis estimate is not an invoice and does not represent the final amount due or the balance on this estimate.\n\nFor questions or concerns, please call Bridgeport Boatworks at (860) 536-9651.","body_zh":"证物 J\n\nBridgeport Boatworks（布里奇波特船厂） 731 SeaviewAve Bridgeport,CT06607 United States (860) 536-9651\n\n舱底板更换 2022 编号：6234\n\n联系人\nLloyd Benard\ncaptain@yachtladymay.com\n1 3057994799\n1.\n舱底\n板\n更换 船只\nLady May（梅夫人号）\n尺寸：151 ' x 32 ' x 7 '\n制造厂：Feadship（斐帝星）\n重量：0\n$2,280.76\n\n备注：1. 依据现有右舷板打样\n2. 所有边缘倒角\n3. 切出吊点孔并边缘倒角\n人工 费率 数量 总计\n分包商人工 BB\n备注：1. 依据现有右舷板打样\n2. 所有边缘倒角\n3. 切出吊点孔并边缘倒角\n交货期 2 周\n颜色可能与原色略有差异 $2,193.04 一口价 1 $2,193.04 N\n收费项目 费率 数量 总计\n环境与安全费 BB 4%（配件与人工） 1 $87.72 N\n人工\n$2,193.04 配件\n$0.00 收费\n$87.72 小计\n$2,280.76 税费\n$0.00 总计\n$2,280.76\n条款与条件\n我们很高兴为您船只的维修工作提供本估价单。\n本预算估价乃基于我们对您船只的检查、您向我们提供的信息，以及我们在此类相似船只和工作方面的经验。在我们的工作开始后，可能会发现您船只存在有缺陷的部件或其他问题，因此，本估价不包括作业开始后可能需要的额外配件或人工。如果出现任何此类问题，我们将通知您。若适用，税费、环境费和分包商费用可能需要另行计收。\n本估价单中所列的价格基于此处所列的假设、除外条款和工作范围，且自估价单出具之日起十四（14）天内有效。\n您对本估价单的接受须受附件附录 A 所载条款与条件的约束。\n批准时须支付估价总额 50% 的定金，余款及任何额外费用须在完工时付清。\n\n若本估价单及条款与条件获得您的认可，请尽早签署并回传。如有任何疑问或顾虑，请随时与我们联系。\n\nBridgeport Boatworks 代表________________________________________________\n\n客户签名\n\n印刷体姓名\n\n日期\n须知\n\n本估价单并非发票，不代表本估价单的最终应付金额或结欠余额。如有疑问或顾虑，请致电 (860) 536-9651 联系 Bridgeport Boatworks。\n附录 A\n\n条款与条件\n\n1. 适用范围：这些条款与条件（“条款”）是规范 Bridgeport Boatworks 向随附估价单（“估价单”）中所列船只（“船只”）的所有人（“所有人”）提供服务（“服务”）的唯一条款。条款和估价单在此统称为“协议”。这些条款应优先于 Bridgeport Boatworks 与所有人之间的任何先前协议或讨论。一旦 Bridgeport Boatworks 开始履行服务，或所有人寄回已签署的协议（以较早发生者为准），所有人即被视为已接受这些条款。\n\n2. 报酬：作为 Bridgeport Boatworks 履行服务的对价，所有人同意在收到 Bridgeport Boatworks 发出的发票后或按照本协议的其他规定，向 Bridgeport Boatworks 支付估价单/发票中所列的费用（或已赚取的部分）。此外，所有人应向 Bridgeport Boatworks 偿付其在履行服务过程中发生的合理费用，包括但不限于差旅费、仓储费、运输费以及 Bridgeport Boatworks 在履行服务过程中发生的其他合理费用。所有人应在收到包含此类费用的发票后支付此类可报销费用。所有人根据本协议应付给 Bridgeport Boatworks 的任何款项，在三十（30）天宽限期后，应自到期日起按适用法律允许的最高利率计息。\n\n3. 变更请求：所有人可随时通过向 Bridgeport Boatworks 提交书面请求（“变更请求”）来请求对服务的任何部分进行变更。在收到所有人的变更请求后的合理时间内，Bridgeport Boatworks 应评估变更请求的影响，并向所有人提供一份书面声明，列出其对变更费用的估算。在收到 Bridgeport Boatworks 的变更请求后的合理时间内，所有人应提供书面接受或拒绝该变更请求的意见。Bridgeport Boatworks 的服务费应根据服务的增加程度进行调整，按双方商定的固定金额计费；或者如果双方未就固定金额达成一致，则按本协议规定的费率，或若未规定费率则按双方商定的费率，以工料计费（T&M）为基础进行调整。若双方未达成书面协议，Bridgeport Boatworks 不得被要求继续进行服务变更。\n\n4. 保证：Bridgeport Boatworks 保证应由具备所需技能、经验和资质的人员以专业和熟练的方式履行服务。除本协议所载内容外，Bridgeport Boatworks 对工艺或材料不作任何明示或暗示的保证，包括对适销性、特定用途适用性或适航性的任何暗示保证。\n\n5. 费用与成本：所有人应向 Bridgeport Boatworks 偿付在催收任何逾期款项过程中发生的所有费用，包括但不限于律师费。除本协议项下或法律上可获得的所有其他补救措施（Bridgeport Boatworks 行使本协议项下的任何权利并不放弃上述补救措施）之外，如果所有人未能按本协议规定支付任何到期款项，Bridgeport Boatworks 有权暂停交付任何货物或暂停履行本协议项下的任何服务。\n\n6. Bridgeport Boatworks 的责任：对于因本协议引起或与本协议相关的任何事项，Bridgeport Boatworks 概不承担任何责任，除非该事项是由 Bridgeport Boatworks 或其直接负责的人员的单独过过失所致。在任何情况下，Bridgeport Boatworks 对因本协议引起或与本协议相关的任何事项所承担的责任均不得超过根据本协议向 Bridgeport Boatworks 支付的费用。Bridgeport Boatworks 的任何负责人、合伙人、成员、董事、高级职员、代理人、受雇人、雇员或顾问均不对与本协议标的事项相关的任何个人责任承担责任。\n\n7. 保险：在服务期间（包括船只由 Bridgeport Boatworks 保管和/或控制期间），所有人应始终就船只保持足额且符合惯例的保险。所有人与 Bridgeport Boatworks 双方特此放弃针对对方就人身伤害、损失或损害的全部追偿权，但以受损方收到保险赔付款的范围为限。本协议要求的所有保单均应规定，各承保人放弃就此类保单项下应付损失的所有代位求偿权。\n\n8. 终止：若所有人严重违反其在本协议项下的义务，Bridgeport Boatworks 有权在发出七（7）天书面通知后终止本协议。若本协议在服务完成前因任何原因终止，则除了本协议详述的可报销费用外，所有人还应向 Bridgeport Boatworks 支付截至终止之日剩余费用的余额，该余额代表复原/遣散成本、机会成本和预期损失利润的付款。Bridgeport Boatworks 行使其在本条项下的权利，绝不以任何方式限制或削减其根据本协议或适用法律可获得的其它补救措施，包括针对该船只的任何留置权。\n\n9. 不可抗力：对于因超出 Bridgeport Boatworks 合理控制范围的行为或情况导致或引起的未能履行或延迟履行本协议任何条款的情况，在上述原因影响的范围内，Bridgeport Boatworks 不对所有人承担责任，亦不被视为违反或违背本协议，上述情况包括但不限于：天灾、洪水、火灾、地震、爆炸、政府行为、战争、恐怖主义威胁或行为、暴乱或其他内乱、公共紧急事件、流行病或大流行病、停工、罢工或其他劳资纠纷，或影响承运人的限制或延误，或无法或延迟获取充足或合适的物资、材料，或电信故障或停电。\n\n10. 一般条款：\n\na. 所有人特此授予 Bridgeport Boatworks 及其代理人和雇员为测试和/或检查目的而操作船只的许可。\n\nb. 所有人应在将船只交付给 Bridgeport Boatworks 之前，从船上移走所有非履行服务所必需的个人财物、用具或其他附属物品。对于遗留在船上的任何此类个人财物、用具或其他附属物品因火灾、盗窃、小偷小摸或其他原因造成的损坏或丢失，Bridgeport Boatworks 概不负责。交付船只并不构成对遗留在船上且非履行服务所必需的任何个人财物、用具或其他附属物品的寄托。\n\nc. 本协议构成双方就本协议标的事项达成的完整协议，并取代所有先前的书面或口头协议。\n\nd. 除非由本协议双方以书面形式作出并签署，否则不得对本协议进行任何变更、修改或修订。\n\ne. 本协议中包含的所有明示陈述、保证、赔偿和责任限制在本协议因任何原因完成或终止后继续有效。如果本协议的任何条款被具有合法管辖权的法院裁定为无效、非法或不可执行，其余条款的有效性、合法性和可执行性绝不应因此受到影响或受损。其余条款应保持完全有效，犹如该不可执行的条款已被删除一样。双方同意以尽可能接近被删条款意图的有效条款替换任何被删除的条款。\n\nf. 本协议受履行服务所在州的法律管辖并据其进行解释，不考虑其法律冲突原则。\n\ng. Bridgeport Boatworks 与所有人应首先尝试通过各自代表之间的讨论来解决争议或分歧，各方代表应在任一方提出请求后尽快会面，以尝试解决此类争议或分歧。如果会面后代表们确定无法按照双方满意的条款解决争议或分歧，双方应将该争议或分歧提交不具有约束力的调解。调解应由双方共同同意的公正调解员主持，或者如果双方无法达成一致，则由美国仲裁协会（“AAA”）指定的调解员主持。如果争议未能按照上述程序解决，则此类争议应根据当时有效的适用 AAA 规则通过仲裁裁决，除非双方另有约定。仲裁员的裁决对双方均为终局并具有约束力，且不得向法院提起上诉。任何具有管辖权的法院均可根据适用法律依据该裁决作出判决。\n须知\n\n本预估单不是发票，不代表最终应付金额或本预估单项下的应付余额。\n\n如有疑问或关切事项，请致电 Bridgeport Boatworks（布里奇波特船厂），电话：(860) 536-9651。","key_entities":["Je","CIPA"],"ecf_references":[],"word_count":1806,"status":"published","published_at":null,"created_at":null,"updated_at":"2026-08-23 13:31:57"}