{"id":"court_ctb_889_10","court":"CTB","case_no":"22-50073","doc_number":889,"sub_number":10,"doc_type":"UNKNOWN","filed_date":"2022-08-11","title":"HK-10 Bridgeport Boatworks 731 Seaview Ave Bridgeport, CT 06607 United States (860) 536-9651","summary_zh":null,"summary_en":null,"body_en":"# **HK-10**\n\nBridgeport Boatworks 731 Seaview Ave Bridgeport, CT 06607 United States (860) 536-9651\n\n\n\nBilge Board Replacement 2022 **ID:** 6234\n\n| Contact
Lloyd Benard
captain@yachtladymay.com
1 3057994799 | | Vessel | Lady May
Dimensions: 151 ' x 32 ' x 7 '
Make: Feadship
Weight: 0 | | | |\n|-------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------|-----------------|--------------------|---------------------------------------------------------------------------|---------------|---------------------|--|\n| 1. Bilge Board Replacement | | | | | \\$2,280.76 | |\n| Comments: 1. Template Existing Starboard Board
2. Bevel all Edges
3. Cut out Holes for lift points and bevel edge | | | | | | |\n| Labor | | | Rate | Qty | Total | |\n| Subcontractor Labor BB
Comments: 1. Template Existing Starboard Board
2. Bevel all Edges
3. Cut out Holes for lift points and bevel edges
Lead Time 2 Weeks
**Color may differ slightly from original Color** | | | \\$2,193.04 Flat Fee | 1 | \\$2,193.04 N | |\n| Charge | | | Rate | Qty | Total | |\n| Environmental & Safety Fee BB | | | 4% (Parts and Labor) | 1 | \\$87.72 N | |\n| Labor
\\$2,193.04 | Parts
\\$0.00 | Charges
\\$87.72 | Subtotal
\\$2,280.76 | Tax
\\$0.00 | Total
\\$2,280.76 | |\n| Terms and Conditions
We are pleased to provide this Estimate for repair work on your vessel.
This Budgetary Estimate is based upon our inspection of your vessel, information that you have provided to us, and
our experience regarding similar vessels and work. It is possible that defective parts or other issues with
your vessel will be discovered after our work has begun and, for these reasons, this Estimate does not
include additional parts or labor that may be required after the job has begun. We will notify you of any
such issues if they should arise. Tax, Environental and Subcontractor charges may be additional if applicable. | | | | | | |\n| The pricing set forth in this Estimate is based on the assumptions, exclusions and scope of work set forth
herein, and is valid for fourteen (14) days from the date of the Estimate. | | | | | | |\n| Your acceptance of this Estimate is subject to the terms and conditions attached hereto as Exhibit A.
A 50% deposit of the Estimate total is required at the time of approval, with the balance and any additional
charges due upon completion. | | | | | | |\n\nShould this Estimate and Terms and Conditions meetwith your approval, kindlysign and return at your earliest convenience. If you have anyquestions or concerns, please do not hesitate to contact us.\n\nBridgeport Boatworks Representative\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\n\nCustomer Signatur\n\nPrinted Nam\n\nDat\n\n#### **Notice**\n\nThis Estimate is not an invoice and does not represent the final amount due or the balance on this Estimate. For questions or concerns, please call Bridgeport Boatworks at (860) 536-9651.\n\n#### Exhibit A\n\nTerms and Conditions\n\n1. Applicability: These terms and conditions (\"Terms\") are the onlyterms which govern the services (\"Services\") to be provided byBridgeport Boatworks to the owner (\"Owner\") of the vessel(s) (\"Vessel\") listed in the accompanying estimate (\"Estimate\"). The Terms and Estimate are collectivelyreferred to herein as the \"Agreement.\" These Terms shall prevail over anyprior agreements or discussions between Bridgeport Boatworks and theOwner.Owner will be deemed to have accepted these Terms upon Bridgeport Boatworks' commencement of performance of the Services orOwner's return of the signed Agreement,whichever is earlier.\n\n2.Compensation: In consideration of the performance byBridgeport Boatworks of the Services,Owner agrees to payBridgeport Boatworks the fee set forth in the Estimate/Invoice (or the portion earned) upon receipt of submission of Bridgeport Boatworks' invoice or as otherwise set forth in the Agreement. In addition,Owner shall reimburse Bridgeport Boatworks for reasonable expenses incurred in performance of the Services, including but not limited to travel expenses, storage charges, shipping charges, and other reasonable expenses incurred in Bridgeport Boatworks' performance of the Services.Owner shall paysuch reimbursable expenses upon receipt followingOwner's receipt of an invoice containing such expenses. Anyamounts due to Bridgeport Boatworks from Owner under this Agreement shall, after a thirty(30) daygrace period, bear interest from the due date at the maximum rate allowed byapplicable law.\n\n3.Change Requests:Owner mayrequest a change to anyportion of the Services at anytime by submitting such request in writing to Bridgeport Boatworks (\"Change Request\"). Within a reasonable time after receipt of a Change Request from Owner, Bridgeport Boatworks shall evaluate the impact of the Change Request and provideOwner with a written statement setting forth its estimate of the cost of the change. Within a reasonable time after receipt of a Change Request from Bridgeport Boatworks,Owner shall provide a written acceptance or rejection of the Change Request. Bridgeport Boatworks' fee for the Services shall be adjusted to the extent of anyincrease in Services, at a fixed amount as agreed bythe parties, or if the parties do not agree to a fixed amount, on a time and\n\nmaterials (T&M) basis at the rates set forth herin, or if no rates are set forth, at rates agreed by the parties. Bridgeport Boatworks shall not be required to proceed with a change in services absent agreement bythe parties in writing.\n\n4. Warranty: Bridgeport Boatworks warrants that the Services shall be performed using personnel of required skill, experience and qualifications in a professional and workmanlike manner.Other than as set forth herein, Bridgeport Boatworks makes no warranties regarding workmanship or materials, either express or implied, including anyimplied warrantyor merchantability, fitness for a particular purpose or seaworthiness.\n\n5. Fees and Costs:Owner shall reimburse Bridgeport Boatworks for all costs incurred in collecting any late payments, including,without limitation, attorneys' fees. In addition to all other remedies available under this Agreement or at law(which Bridgeport Boatworks does notwaive bythe exercise of anyrights hereunder), Bridgeport Boatworks shall be entitled to suspend the deliveryof anygoods or performance of anyservices hereunder if theOwner fails to payanyamounts when due hereunder.\n\n6. Liabilityof Bridgeport Boatworks: Bridgeport Boatworks shall have no liabilityfor anymatters arising out of or related to this Agreement except to the extent caused bythe sole negligence of Bridgeport Boatworks or those for whom it is directlyresponsible. In no event shall Bridgeport Boatworks' liabilityfor anymatters arising out of or related to this Agreement exceed the fee paid to Bridgeport Boatworks under this Agreement.No principal, partner, member, director, officer, agent, servant, employee, or consultant of Bridgeport Boatworks shall have anypersonal liabilityrelating to the subject matter of this Agreement.\n\n7. Insurance:Owner shall at all times maintain adequate and customaryinsurance covering the Vessel for the duration of the Services, including while the Vessel is in the custodyand/or control of Bridgeport Boatworks.Owner and Bridgeport Boatworks each herebywaive their entire right of recoveryagainst the other for injury, loss, or damage to the extent covered byinsurance proceeds received bythe damaged party. All policies required hereunder shall provide that the respective carrier(s) waives all rights of subrogation with respect to losses payable under such policies.\n\n8. Termination: Bridgeport Boatworks shall have the right to terminate this Agreement upon seven (7) days' written notice in the event thatOwner is in material breach of its obligations hereunder. In the event the Agreement is terminated for anyreason prior to the completion of the Services, then, in addition to the reimbursable expenses detailed herein,Owner shall payto Bridgeport Boatworks the balance of the remaining fee as of the date of termination, representing payment for demobilization costs, opportunitycosts, and anticipated lost profit. Bridgeport Boatworks' exercise of its rights under this section shall not in anywaylimit or abridge other remedies available to it under the Agreement or applicable law, including anylien rights with respect to the Vessel.\n\n9. Force Majeure: Bridgeport Boatworks shall not be liable or responsible to theOwner, nor be deemed to have defaulted or breached this Agreement, for anyfailure or delayin fulfilling or performing any term of this Agreementwhen and to the extent such failure or delayis caused byor results from acts or circumstances beyond the reasonable control of Bridgeport Boatworks including,without\n\nlimitation, acts ofGod, flood, fire, earthquake, explosion, governmental actions,war, terrorist threats or acts, riot, or other civil unrest, public emergency, epidemics or pandemics, lockouts, strikes or other labor disputes, or restraints or delays affecting carriers or inabilityor delayin obtaining supplies\n\n## Case 22-50073 Doc 728-10 Filed 08/11/22 Entered 08/11/22 14:41:45 Page 5 of 5 889-10 09/28/22 09/28/22 15:37:52\n\nother labor disputes, or restraints or delays affecting carriers or inabilityor delayin obtaining supplies\n\nof adequate or suitable materials, materials or telecommunication breakdown or power outage.\n\n10.General Provisions:\n\na. Owner herebygrants Bridgeport Boatworks, its agents and employees, permission to operate the Vessel for the purpose of testing and/or inspection.\n\nb. Owner shall remove all articles of personal property, gear, or other appurtenances not necessary for the performance of the Services from the Vessel prior to deliveryof the Vessel to\n\nBridgeport Boatworks. Bridgeport Boatworks shall not be responsible for damage to or loss of anysuch articles of personal property, gear, or other appurtenances left aboard the Vessel, due to fire, theft, pilferage, or otherwise.Deliveryof the Vessel does not constitute a bailment of anyarticles of personal property, gear, or other appurtenances left on the Vessel which are not necessaryfor the performance of the Services.\n\nc. This Agreement constitutes the entire agreement between the parties hereto regarding the subject matter hereof, and supersedes all prior agreements,whether written or oral.\n\nd.No change, modification, or amendment shall be made to this Agreement unless set forth in writing and signed bythe parties hereto.\n\ne. All express representations,warranties, indemnifications, and limits of liabilityincluded in this Agreementwill survive its completion or termination for anyreason. If anyprovision of this Agreement shall be held invalid, illegal or unenforceable bya court of competent jurisdiction, the validity, legalityand enforceabilityof the remaining provisions shall in no waybe affected or impaired thereby. The remaining provisions shall remain in full force and effect, as if the unenforceable provision had been deleted. The parties agree to replace anyomitted provision with a valid provision that comes as close as possible to the intent of the omitted provision. f. This Agreement shall be governed byand construed under the laws of the state in which the\n\nServices are performed,without regard to its conflicts of laws principles.\n\ng. Bridgeport Boatworks andOwner will first attempt to resolve disputes or disagreements through discussions between their respective representatives,who shall meet upon the request of either partyas soon as convenientlypossible to attempt to resolve such dispute or disagreement. If after meeting, the representatives determine that the dispute or disagreement cannot be resolved on terms satisfactoryto both parties, the parties shall submit the dispute or disagreement to non-binding mediation. The mediation shall be conducted bya mutually agreeable impartial mediator, or if the parties cannot so agree, a mediator designated bythe American Arbitration Association (\"AAA\"). If a dispute has not been resolved in accordance with the procedures set forth above, such disputes shall be decided byarbitration in accordance with the applicable AAArules then in effect, unless the parties mutuallyagree otherwise. The award of the arbitrator(s) shall be final and binding upon the parties without the right of appeal to the courts. Judgment maybe entered upon it in accordance with applicable lawbyanycourt having jurisdiction thereof.\n\n### **Notice**\n\nThis estimate is not an invoice and does not represent the final amount due or the balance on this estimate.\n\nFor questions or concerns, please call Bridgeport Boatworks at (860) 536-9651.","body_zh":"HK-10\n\nBridgeport Boatworks（布里奇波特造船厂） 731 Seaview Ave Bridgeport, CT 06607 United States（美国） (860) 536-9651\n\n舭龙骨板更换 2022 编号：6234\n\n联系人\nLloyd Benard（劳埃德·贝纳德）\ncaptain@yachtladymay.com\n1 3057994799 船只 Lady May（梅夫人号）\n尺寸：151 英尺 x 32 英尺 x 7 英尺\n制造商：Feadship（斐帝星）\n重量：0\n\n1. 舭龙骨板更换 $2,280.76\n备注：1. 以现有右舷龙骨板为样板\n2. 所有边缘打倒角\n3. 切出起吊点孔位并对边缘打倒角\n人工 费率 数量 总计\n分包商人工 BB\n备注：1. 以现有右舷龙骨板为样板\n2. 所有边缘打倒角\n3. 切出起吊点孔位并对边缘打倒角\n交付周期 2 周\n颜色可能与原色略有差异 $2,193.04 固定费用 1 $2,193.04 N\n费用项目 费率 数量 总计\n环保与安全费 BB 4%（配件与人工） 1 $87.72 N\n人工\n$2,193.04 配件\n$0.00 杂费\n$87.72 小计\n$2,280.76 税费\n$0.00 总计\n$2,280.76\n条款与条件\n我们很高兴为贵方船只的维修工程提供此份估价单。\n此预算估价单基于我们对贵方船只的检查、贵方向我们提供的信息，以及我们对类似船只和工程的经验。在我们的工作开始后，可能会发现贵方船只存在有缺陷的零件或其他问题，出于这些原因，本估价单不包括开工后可能需要的额外配件或人工。如果出现此类问题，我们将通知贵方。税费、环保费和分包商费用（若适用）可能需另行计费。\n本估价单中所列的价格基于本文所载的假设、除外条款和工作范围，自估价单出具之日起十四（14）天内有效。\n贵方对本估价单的接受须受附件附录 A 所附条款与条件的约束。\n在批准时需支付估价单总额 50% 的定金，余款及任何额外费用在完工时付清。\n\n若本估价单及条款与条件获得贵方认可，请尽快签署并退回。如有任何疑问或关切，请随时与我们联系。\n\nBridgeport Boatworks 代表___________________________________________________\n\n客户签名\n\n正楷姓名\n\n日期\n须知\n\n本估价单并非发票，亦不代表最终应付金额或本估价单的结欠款项。如有疑问或关切，请致电 Bridgeport Boatworks，电话：(860) 536-9651。\n附录 A\n\n条款与条件\n\n1. 适用范围：本条款与条件（“本条款”）是管辖 Bridgeport Boatworks 向随附估价单（“估价单”）所列船只（“船只”）的所有人（“所有人”）提供服务（“服务”）的唯一条款。本条款与估价单在本文中合称为“本协议”。本条款应优于 Bridgeport Boatworks 与所有人之间先前的任何协议或讨论。所有人一旦在 Bridgeport Boatworks 开始履行服务，或所有人寄回经签署的本协议（以较早发生者为准），即被视为已接受本条款。\n\n2. 报酬：作为 Bridgeport Boatworks 履行服务的对价，所有人同意在收到 Bridgeport Boatworks 提交的发票后或按照本协议另行规定的方式，向 Bridgeport Boatworks 支付估价单/发票中规定的费用（或已挣得的部分）。此外，所有人应向 Bridgeport Boatworks 偿还其在履行服务过程中产生的合理费用，包括但不限于差旅费、仓储费、运费以及 Bridgeport Boatworks 在履行服务过程中产生的其他合理费用。所有人在收到包含此类费用的发票后，应在收到时支付此类应报销费用。所有人根据本协议应向 Bridgeport Boatworks 支付的任何款项，在三十（30）天的宽限期过后，应自到期日起按适用法律允许的最高利率计息。\n\n3. 变更请求：所有人可随时通过向 Bridgeport Boatworks 提交书面请求，请求对服务的任何部分进行变更（“变更请求”）。在收到所有人的变更请求后的合理时间内，Bridgeport Boatworks 应评估该变更请求的影响，并向所有人提供一份书面声明，列出其对变更费用的估算。在收到 Bridgeport Boatworks 的变更请求后的合理时间内，所有人应提供对该变更请求的书面接受或拒绝。Bridgeport Boatworks 的服务费用应根据服务的增加程度进行调整，调整方式为按双方商定的固定金额计算，或者如果双方未能商定固定金额，则按本文规定的工料费（T&M）费率计算，若未规定费率，则按双方商定的费率计算。若双方未达成书面协议，Bridgeport Boatworks 不得被要求进行服务变更。\n\n4. 保证：Bridgeport Boatworks 保证应由具备所需技能、经验和资质的人员以专业且熟练的方式履行服务。除本文规定外，Bridgeport Boatworks 对工艺或材料不作任何明示或暗示的保证，包括对适销性、特定用途适用性或适航性的任何默示保证。\n\n5. 费用与成本：所有人应向 Bridgeport Boatworks 赔偿其因追讨任何逾期款项而产生的所有成本，包括但不限于律师费。除本协议或法律规定的所有其他救济措施（Bridgeport Boatworks 行使本协议项下的任何权利并不放弃上述救济）之外，如果所有人未能支付本协议项下的任何到期款项，Bridgeport Boatworks 有权暂停交付任何货物或暂停履行本协议项下的任何服务。\n\n6. Bridgeport Boatworks 的责任：Bridgeport Boatworks 对因本协议引起的或与本协议相关的任何事项均不承担任何责任，除非该责任是由 Bridgeport Boatworks 或其直接负责的人员的单独过失造成的。在任何情况下，Bridgeport Boatworks 因本协议引起的或与本协议相关的任何事项所承担的责任均不得超过根据本协议已支付给 Bridgeport Boatworks 的费用。Bridgeport Boatworks 的任何负责人、合伙人、成员、董事、高级管理人员、代理人、雇员、雇工或顾问均不对与本协议标的事项相关的任何个人责任承担责任。\n\n7. 保险：在服务期间（包括船只由 Bridgeport Boatworks 保管和/或控制期间），所有人应始终维持对船只充分且惯常的保险。所有人与 Bridgeport Boatworks 双方特此放弃就受损方收到的保险理赔金范围内的伤害、损失或损害向对方追偿的全部权利。本协议要求的所有保单均应规定各承保人放弃对该等保单项下应付损失的所有代位追偿权。\n\n8. 终止：如果所有人严重违反其在本协议项下的义务，Bridgeport Boatworks 有权在提前七（7）天发出书面通知后终止本协议。若本协议在服务完成前因任何原因终止，则除本文详述的应报销费用外，所有人应向 Bridgeport Boatworks 支付截至终止之日剩余费用的余额，以作为对遣散成本、机会成本和预期利润损失的补偿。Bridgeport Boatworks 行使其在本条项下的权利，绝不限制或削弱其根据本协议或适用法律可获得的其它救济措施，包括对该船只的任何留置权。\n\n9. 不可抗力：对于因超出 Bridgeport Boatworks 合理控制范围的行为或情况导致未能履行或延迟履行本协议任何条款的情况，Bridgeport Boatworks 不对所有人承担责任，亦不被视为违约或违反本协议，此类情况包括但不\n\n限于天灾、洪水、火灾、地震、爆炸、政府行为、战争、恐怖主义威胁或行为、暴乱或其他内乱、公共紧急事件、流行病或大流行病、停工、罢工或其他劳动争议，或影响承运人的限制或延误，或无法获得或延迟获得\nCase 22-50073 Doc 728-10 Filed 08/11/22 Entered 08/11/22 14:41:45 Page 5 of 5 889-10 09/28/22 09/28/22 15:37:52\n\n其他劳动争议，或影响承运人的限制或延误，或无法获得或延迟获得\n\n充足或合适的材料、材料或电信故障或停电。\n\n10. 一般条款：\n\na. 所有人特此授予 Bridgeport Boatworks 及其代理人和雇员为测试和/或检查目的操作该船只的许可。\n\nb. 所有人应在将船只交付给\n\nBridgeport Boatworks 之前，从船只上移走所有非履行服务所必需的个人财产物品、属具或其他附属设备。Bridgeport Boatworks 对因火灾、盗窃、小偷小摸或其他原因留在船上的任何此类个人财产物品、属具或其他附属设备的损坏或遗失概不负责。交付船只并不构成对遗留在船上且非履行服务所必需的任何个人财产物品、属具或其他附属设备的寄托保管。\n\nc. 本协议构成双方就本协议标的事项达成的完整协议，并取代之前所有的书面或口头协议。\n\nd. 除非以书面形式作出并由本协议双方签署，否则不得对本协议进行任何变更、修改或修订。\n\ne. 本协议中包含的所有明示陈述、保证、保障赔偿和责任限制在本协议因任何原因完成或终止后继续有效。若本协议的任何条款被具有管辖权的法院裁定为无效、非法或不可执行，其余条款的有效性、合法性和可执行性绝不应因此受到影响或受损。其余条款应保持完全有效，犹如该不可执行的条款已被删除一样。双方同意以尽可能接近被省略条款意图的有效条款替换任何被省略的条款。 f. 本协议应受履行\n\n服务所在州的法律管辖并依其解释，不考虑其法律冲突原则。\n\ng. Bridgeport Boatworks（布里奇波特船厂）与 Owner（船东）将首先尝试通过各自代表之间的讨论来解决争议或分歧，代表们应在任何一方提出请求后尽快且方便时会面，以尝试解决该争议或分歧。如果在会面后，代表们认定无法在双方满意的条款下解决争议或分歧，双方应将争议或分歧提交给不具约束力的调解。调解应由双方均同意的公正调解员主持；如果双方无法达成一致，则由 American Arbitration Association（美国仲裁协会，简称“AAA”）指定的调解员主持。如果争议未按照上述程序得到解决，除非双方另有约定，此类争议应根据当时有效的适用 AAA 规则通过仲裁裁决。仲裁员作出的裁决应为终局裁决，对双方具有约束力，且不得向法院提起上诉。任何具有管辖权的法院均可根据适用法律依据该裁决作出判决。\n\n通知\n\n本估算单不是发票，不代表最终应付金额或本估算单上的余额。\n\n如有疑问或顾虑，请致电 Bridgeport Boatworks（布里奇波特船厂），电话：(860) 536-9651。","key_entities":["Je","CIPA"],"ecf_references":[{"doc_number":728,"court":"CTB"}],"word_count":1850,"status":"published","published_at":"2022-08-11 00:00:00","created_at":"2022-08-11","updated_at":"2026-08-23 13:35:13"}