{"id":"court_ctb_889_2","court":"CTB","case_no":"22-50073","doc_number":889,"sub_number":2,"doc_type":"UNKNOWN","filed_date":"2022-08-11","title":"HK-2 Bridgeport Boatworks 731 SeaviewAve Bridgeport,CT06607 United States (860) 536-9651","summary_zh":null,"summary_en":null,"body_en":"# **HK-2**\n\nBridgeport Boatworks 731 SeaviewAve Bridgeport,CT06607 United States (860) 536-9651\n\nLADY MAY- HAUL OUT 2022 **ID:** 6240\n\n| Contact                  | Vessel                         |\n|--------------------------|--------------------------------|\n| Lloyd Benard             | Lady May                       |\n| captain@yachtladymay.com | Dimensions: 151 ' x 32 ' x 7 ' |\n| 1 3057994799             | Make: Feadship                 |\n|                          | Weight: 0                      |\n|                          |                                |\n\n# **1. 700 Haul & Launch Up To 330T Or Max 150' BB \\$13,117.52**\n\n# Labor **Rate** Qty **Total** 700 Haul & Launch Up To 430T Max 180' BB \\$55.00 Per Foot 151 ft \\$8,305.00 N Blocking \\$7 Per Foot BB \\$7.00 Per Foot flat 151 \\$1,057.00 N Diver Fee BB \\$1,600.00 Flat Fee 1 \\$1,600.00 N Naval Architect BB \\$1,500.00 Flat Fee 1 \\$1,500.00 N\n\n| Part |                      |                               |                     | Qty<br>Rate             |               | Total                |\n|------|----------------------|-------------------------------|---------------------|-------------------------|---------------|----------------------|\n|      | Blocking Materials   |                               |                     | \\$1.00                  | 151           | \\$151.00 N           |\n|      | Charge               |                               |                     | Rate                    | Qty           | Total                |\n|      |                      | Environmental & Safety Fee BB |                     | 4% (Parts and Labor)    | 1             | \\$504.52 N           |\n|      | Labor<br>\\$12,462.00 | Parts<br>\\$151.00             | Charges<br>\\$504.52 | Subtotal<br>\\$13,117.52 | Tax<br>\\$0.00 | Total<br>\\$13,117.52 |\n\n# **Terms and Conditions**\n\nWe are pleased to provide this Estimate for repair work on your vessel.\n\nThis BudgetaryEstimate is based upon our inspection of your vessel, information that you have provided to us, and our experience regarding similar vessels and work. It is possible that defective parts or other issues with your vessel will be discovered after our work has begun and, for these reasons, this Estimate does not include additional parts or labor that maybe required after the job has begun. We will notifyyou of any such issues if theyshould arise. Tax, Environental and Subcontractor charges maybe additional if applicable.\n\nThe pricing set forth in this Estimate is based on the assumptions, exclusions and scope ofwork set forth herein, and is valid for fourteen (14) days from the date of the Estimate.\n\nYour acceptance of this Estimate is subject to the terms and conditions attached hereto as Exhibit A.\n\nAdeposit is required at the time of approval,with the balance and anyadditional charges due upon completion.\n\n| Apayment schedule will be provided byBridgeport Boatworks, laying out the estimated expenses for the upcoming |\n|---------------------------------------------------------------------------------------------------------------|\n| months work. This will allowthe customer to budget/make payment on a monthlybasis and keep account in the     |\n| positive at all times.                                                                                        |\n\nShould this Estimate and Terms and Conditions meetwith your approval, kindlysign and return at your earliest convenience. If you have anyquestions or concerns, please do not hesitate to contact us.\n\n#### Sincerely,\n\nBridgeport Boatworks Representative\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\\_\n\nCustomer Signatur Printed Nam\n\nDat\n\n#### **Notice**\n\nThis Estimate is not an invoice and does not represent the final amount due or the balance on this Estimate. For questions or concerns, please call Bridgeport Boatworks at (860) 536-9651.\n\n#### Exhibit A\n\nTerms and Conditions\n\n1. Applicability: These terms and conditions (\"Terms\") are the onlyterms which govern the services (\"Services\") to be provided byBridgeport Boatworks to the owner (\"Owner\") of the vessel(s) (\"Vessel\") listed in the accompanying estimate (\"Estimate\"). The Terms and Estimate are collectivelyreferred to herein as the \"Agreement.\" These Terms shall prevail over anyprior agreements or discussions between Bridgeport Boatworks and theOwner.Owner will be deemed to have accepted these Terms upon Bridgeport Boatworks' commencement of performance of the Services orOwner's return of the signed Agreement,whichever is earlier.\n\n2.Compensation: In consideration of the performance byBridgeport Boatworks of the Services,Owner agrees to payBridgeport Boatworks the fee set forth in the Estimate/Invoice (or the portion earned) upon receipt of submission of Bridgeport Boatworks' invoice or as otherwise set forth in the Agreement. In addition,Owner shall reimburse Bridgeport Boatworks for reasonable expenses incurred in performance of the Services, including but not limited to travel expenses, storage charges, shipping charges, and other reasonable expenses incurred in Bridgeport Boatworks' performance of the Services.Owner shall paysuch reimbursable expenses upon receipt followingOwner's receipt of an invoice containing such expenses. Anyamounts due to Bridgeport Boatworks from Owner under this Agreement shall, after a thirty(30) daygrace period, bear interest from the due date at the maximum rate allowed byapplicable law.\n\n3.Change Requests:Owner mayrequest a change to anyportion of the Services at anytime by submitting such request in writing to Bridgeport Boatworks (\"Change Request\"). Within a reasonable time after receipt of a Change Request from Owner, Bridgeport Boatworks shall evaluate the impact of the Change Request and provideOwner with a written statement setting forth its estimate of the\n\ncost of the change. Within a reasonable time after receipt of a Change Request from Bridgeport Boatworks,Owner shall provide a written acceptance or rejection of the Change Request. Bridgeport Boatworks' fee for the Services shall be adjusted to the extent of anyincrease in Services, at a fixed amount as agreed bythe parties, or if the parties do not agree to a fixed amount, on a time and materials (T&M) basis at the rates set forth herin, or if no rates are set forth, at rates agreed by the parties. Bridgeport Boatworks shall not be required to proceed with a change in services absent agreement bythe parties in writing.\n\n4. Warranty: Bridgeport Boatworks warrants that the Services shall be performed using personnel of required skill, experience and qualifications in a professional and workmanlike manner.Other than as set forth herein, Bridgeport Boatworks makes no warranties regarding workmanship or materials, either express or implied, including anyimplied warrantyor merchantability, fitness for a particular purpose or seaworthiness.\n\n5. Fees and Costs:Owner shall reimburse Bridgeport Boatworks for all costs incurred in collecting any late payments, including,without limitation, attorneys' fees. In addition to all other remedies available under this Agreement or at law(which Bridgeport Boatworks does notwaive bythe exercise of anyrights hereunder), Bridgeport Boatworks shall be entitled to suspend the deliveryof anygoods or performance of anyservices hereunder if theOwner fails to payanyamounts when due hereunder.\n\n6. Liabilityof Bridgeport Boatworks: Bridgeport Boatworks shall have no liabilityfor anymatters arising out of or related to this Agreement except to the extent caused bythe sole negligence of Bridgeport Boatworks or those for whom it is directlyresponsible. In no event shall Bridgeport Boatworks' liabilityfor anymatters arising out of or related to this Agreement exceed the fee paid to Bridgeport Boatworks under this Agreement.No principal, partner, member, director, officer, agent, servant, employee, or consultant of Bridgeport Boatworks shall have anypersonal liabilityrelating to the subject matter of this Agreement.\n\n7. Insurance:Owner shall at all times maintain adequate and customaryinsurance covering the Vessel for the duration of the Services, including while the Vessel is in the custodyand/or control of Bridgeport Boatworks.Owner and Bridgeport Boatworks each herebywaive their entire right of recoveryagainst the other for injury, loss, or damage to the extent covered byinsurance proceeds received bythe damaged party. All policies required hereunder shall provide that the respective carrier(s) waives all rights of subrogation with respect to losses payable under such policies.\n\n8. Termination: Bridgeport Boatworks shall have the right to terminate this Agreement upon seven (7) days' written notice in the event thatOwner is in material breach of its obligations hereunder. In the event the Agreement is terminated for anyreason prior to the completion of the Services, then, in addition to the reimbursable expenses detailed herein,Owner shall payto Bridgeport Boatworks the balance of the remaining fee as of the date of termination, representing payment for demobilization costs, opportunitycosts, and anticipated lost profit. Bridgeport Boatworks' exercise of its rights under this section shall not in anywaylimit or abridge other remedies available to it under the Agreement or applicable law, including anylien rights with respect to the Vessel.\n\n9. Force Majeure: Bridgeport Boatworks shall not be liable or responsible to theOwner, nor be deemed to have defaulted or breached this Agreement, for anyfailure or delayin fulfilling or performing any term of this Agreementwhen and to the extent such failure or delayis caused byor results from acts\n\n# Case 22-50073 Doc 728-2 Filed 08/11/22 Entered 08/11/22 14:41:45 Page 5 of 6 889-2 09/28/22 09/28/22 15:37:52\n\nterm of this Agreementwhen and to the extent such failure or delayis caused byor results from acts or circumstances beyond the reasonable control of Bridgeport Boatworks including,without limitation, acts ofGod, flood, fire, earthquake, explosion, governmental actions,war, terrorist threats or acts, riot, or other civil unrest, public emergency, epidemics or pandemics, lockouts, strikes or other labor disputes, or restraints or delays affecting carriers or inabilityor delayin obtaining supplies of adequate or suitable materials, materials or telecommunication breakdown or power outage.\n\n10.General Provisions:\n\na. Owner herebygrants Bridgeport Boatworks, its agents and employees, permission to operate the Vessel for the purpose of testing and/or inspection.\n\nb. Owner shall remove all articles of personal property, gear, or other appurtenances not necessary for the performance of the Services from the Vessel prior to deliveryof the Vessel to Bridgeport Boatworks. Bridgeport Boatworks shall not be responsible for damage to or loss of anysuch articles of personal property, gear, or other appurtenances left aboard the Vessel, due to fire, theft, pilferage, or otherwise.Deliveryof the Vessel does not constitute a bailment of anyarticles of personal property, gear, or other appurtenances left on the Vessel which are not necessaryfor the performance of the Services.\n\nc. This Agreement constitutes the entire agreement between the parties hereto regarding the subject matter hereof, and supersedes all prior agreements,whether written or oral. d.No change, modification, or amendment shall be made to this Agreement unless set forth in writing and signed bythe parties hereto.\n\ne. All express representations,warranties, indemnifications, and limits of liabilityincluded in this Agreementwill survive its completion or termination for anyreason. If anyprovision of this Agreement shall be held invalid, illegal or unenforceable bya court of competent jurisdiction, the validity, legalityand enforceabilityof the remaining provisions shall in no waybe affected or impaired thereby. The remaining provisions shall remain in full force and effect, as if the unenforceable provision had been deleted. The parties agree to replace anyomitted provision with a valid provision that comes as close as possible to the intent of the omitted provision. f. This Agreement shall be governed byand construed under the laws of the state in which the Services are performed,without regard to its conflicts of laws principles.\n\ng. Bridgeport Boatworks andOwner will first attempt to resolve disputes or disagreements through discussions between their respective representatives,who shall meet upon the request of either partyas soon as convenientlypossible to attempt to resolve such dispute or disagreement. If after meeting, the representatives determine that the dispute or disagreement cannot be resolved on terms satisfactoryto both parties, the parties shall submit the dispute or disagreement to non-binding mediation. The mediation shall be conducted bya mutually agreeable impartial mediator, or if the parties cannot so agree, a mediator designated bythe American Arbitration Association (\"AAA\"). If a dispute has not been resolved in accordance with the procedures set forth above, such disputes shall be decided byarbitration in accordance with the applicable AAArules then in effect, unless the parties mutuallyagree otherwise. The award of the arbitrator(s) shall be final and binding upon the parties without the right of appeal to the courts. Judgment maybe entered upon it in accordance with applicable lawbyanycourt having jurisdiction thereof.\n\n### **Notice**\n\nThis estimate is not an invoice and does not represent the final amount due or the balance on this estimate.\n\n# Case 22-50073 Doc 728-2 Filed 08/11/22 Entered 08/11/22 14:41:45 Page 6 of 6 889-2 09/28/22 09/28/22 15:37:52\n\nThis estimate is not an invoice and does not represent the final amount due or the balance on this estimate.\n\nFor questions or concerns, please call Bridgeport Boatworks at (860) 536-9651.","body_zh":"HK-2\n\nBridgeport Boatworks（布里奇波特船厂） 731 SeaviewAve Bridgeport,CT06607 United States（美国） (860) 536-9651\n\nLADY MAY（梅夫人号）- 2022年起吊上岸 编号：6240\n\n联系人 船只\n\nLloyd Benard（劳埃德·贝纳德） Lady May\ncaptain@yachtladymay.com 尺寸：151英尺 x 32英尺 x 7英尺\n1 3057994799 制造厂商：Feadship（斐帝星）\n重量：0\n\n1. 700 起吊及下水 至多330吨或最大150英尺 BB $13,117.52\n人工 费率 数量 总计 700 起吊及下水 至多430吨 最大180英尺 BB 每英尺$55.00 151英尺 $8,305.00 N 支墩支撑 每英尺$7 BB 每英尺$7.00 固定 151 $1,057.00 N 潜水员费用 BB $1,600.00 固定费用 1 $1,600.00 N 造船工程师 BB $1,500.00 固定费用 1 $1,500.00 N\n\n配件 数量\n费率 总计\n\n支墩材料 $1.00 151 $151.00 N\n收费项目 费率 数量 总计\n环境与安全费 BB 4%（配件及人工） 1 $504.52 N\n人工\n$12,462.00 配件\n$151.00 收费项目\n$504.52 小计\n$13,117.52 税费\n$0.00 总计\n$13,117.52\n条款与条件\n\n我们很高兴为您船只的维修工作提供本估价单。\n\n本预算估价基于我们对您船只的检查、您向我们提供的信息以及我们关于类似船只和工作的经验。在我们的工作开始后，可能会发现有缺陷的配件或您船只的其他问题，出于这些原因，本估价不包括作业开始后可能需要的额外配件或人工。如果出现任何此类问题，我们将通知您。税费、环境费及分包商费用（若适用）可能另外计费。\n\n本估价单中列出的定价基于此处阐述的假设、除外条款和工作范围，自估价单出具之日起十四（14）天内有效。\n\n您对本估价单的接受须受作为附件A附于此处的条款与条件之约束。\n\n批准时须支付定金，余款及任何额外费用在完工时付清。\n\nBridgeport Boatworks 将提供付款计划表，列明未来\n\n几个月工作的预估开支。这将使客户能够按月进行预算/付款，并始终保持账户余额为正。\n\n如本估价单及条款与条件获得您的批准，请尽早签署并寄回。如果您有任何问题或疑虑，请随时与我们联系。\n此致，\n\nBridgeport Boatworks 代表__________________________________________________\n\n客户签名 印刷体姓名\n\n日期\n须知\n\n本估价单不是发票，不代表最终应付金额或本估价单上的余额。如有疑问或顾虑，请致电 (860) 536-9651 联系 Bridgeport Boatworks。\n附件 A\n\n条款与条件\n\n1. 适用性：这些条款与条件（“条款”）是管辖 Bridgeport Boatworks 向随附估价单（“估价单”）中所列船只（“船只”）的所有人（“所有人”）提供服务（“服务”）的唯一条款。条款和估价单在此统称为“协议”。这些条款应优先于 Bridgeport Boatworks 与所有人之间的任何先前协议或讨论。在 Bridgeport Boatworks 开始履行服务或所有人寄回已签署的协议时（以较早者为准），所有人即应被视为已接受这些条款。\n\n2. 报酬：作为 Bridgeport Boatworks 履行服务的对价，所有人同意在收到 Bridgeport Boatworks 提交的发票时或按照协议另行规定的方式，向 Bridgeport Boatworks 支付估价单/发票中列明的费用（或已赚取的部分）。此外，所有人应补偿 Bridgeport Boatworks 在履行服务过程中产生的合理开支，包括但不限于差旅费、仓储费、运输费以及在 Bridgeport Boatworks 履行服务过程中产生的其他合理开支。所有人应在收到载有该等开支的发票后支付该等应予补偿的开支。所有人根据本协议应付给 Bridgeport Boatworks 的任何款项，在三十（30）天的宽限期后，应自到期日起按适用法律允许的最高利率计息。\n\n3. 变更请求：所有人可随时通过向 Bridgeport Boatworks 提交书面请求的方式，请求对服务的任何部分进行变更（“变更请求”）。在收到所有人的变更请求后的合理时间内，Bridgeport Boatworks 应评估变更请求的影响，并向所有人提供一份书面声明，列出其对\n\n变更费用的估计。在收到 Bridgeport Boatworks 的变更请求后的合理时间内，所有人应提供对该变更请求的书面接受或拒绝。Bridgeport Boatworks 的服务费用应根据服务的任何增加进行调整，按双方商定的固定金额调整，或者如果双方未商定固定金额，则按本协议规定的费率以工料计算（T&M）为基础调整，若未规定费率，则按双方商定的费率调整。在双方未达成书面协议的情况下，Bridgeport Boatworks 不得被要求继续进行服务变更。\n\n4. 保证：Bridgeport Boatworks 保证服务应由具备所需技能、经验和资质的人员以专业和熟练工的方式进行。除本协议另有规定外，Bridgeport Boatworks 对工艺或材料不作任何明示或暗示的保证，包括对适销性、特定用途适用性或适航性的任何暗示保证。\n\n5. 费用与成本：所有人应补偿 Bridgeport Boatworks 因催收任何逾期付款而产生的所有费用，包括但不限于律师费。除本协议或法律项下可获得的全部其他救济之外（Bridgeport Boatworks 并不因行使其在本协议项下的任何权利而放弃该等救济），如果所有人未能支付本协议项下的任何到期款项，Bridgeport Boatworks 有权暂停交付任何货物或履行本协议项下的任何服务。\n\n6. Bridgeport Boatworks 的责任：Bridgeport Boatworks 对因本协议引起的或与本协议相关的任何事项不承担任何责任，除非该事项是由 Bridgeport Boatworks 或其直接负责的人员的单独过失造成的。在任何情况下，Bridgeport Boatworks 对因本协议引起的或与本协议相关的任何事项所承担的责任均不得超过根据本协议已支付给 Bridgeport Boatworks 的费用。Bridgeport Boatworks 的任何负责人、合伙人、成员、董事、管理人员、代理人、受雇人、雇员或顾问均不对与本协议标的有关的事项承担任何个人责任。\n\n7. 保险：所有人应在服务期间（包括船只处于 Bridgeport Boatworks 的保管和/或控制之下期间）始终为船只维持充分且符合惯例的保险。所有人与 Bridgeport Boatworks 特此各自放弃就受损方收到的保险收益所涵盖的人身伤害、损失或损害向对方追偿的全部权利。本协议项下所要求的所有保单均应规定，各承保人放弃对根据该等保单应予赔付的损失的所有代位求偿权。\n\n8. 终止：在所有人严重违反其在本协议项下义务的情况下，Bridgeport Boatworks 有权在提前七（7）天发出书面通知后终止本协议。如果本协议在服务完成前因任何原因终止，则除本协议详述的应予补偿的开支外，所有人还应向 Bridgeport Boatworks 支付截至终止之日剩余费用的余额，该余额代表复原/撤场费用、机会成本及预期预期利润损失的款项。Bridgeport Boatworks 行使其在本条项下的权利，不得以任何方式限制或剥夺其根据本协议或适用法律可获得的其他救济，包括对船只的任何留置权。\n\n9. 不可抗力：Bridgeport Boatworks 不对所有人承担责任，亦不应被视为违约或违反本协议，如果且仅在由于超出 Bridgeport Boatworks 合理控制范围的行为\n案号 22-50073 文件 728-2 提交于 08/11/22 录入于 08/11/22 14:41:45 第 5 页 共 6 页 889-2 09/28/22 09/28/22 15:37:52\n\n履行或执行本协议任何条款发生任何未能履行或延误，且该等未能履行或延误是由超出 Bridgeport Boatworks 合理控制范围的行为或情况所引起或导致时，包括但不限于天灾、水灾、火灾、地震、爆炸、政府行为、战争、恐怖威胁或行为、暴乱或其他内乱、公共紧急事件、流行病或大流行病、停工、罢工或其他劳资纠纷，或影响承运人的限制或延误，或无法获得或延误获得充足或合适材料的供应、材料或电信故障或停电。\n\n10. 一般条款：\n\na. 所有人特此授权 Bridgeport Boatworks、其代理人及雇员为测试和/或检查之目的操作船只。\n\nb. 所有人应在将船只交付给 Bridgeport Boatworks 之前，从船只上移走履行服务所非必需的所有个人财产物品、用具或其他附属设备。Bridgeport Boatworks 对因火灾、盗窃、小偷小摸或其他原因造成的留在船上的任何此类个人财产物品、用具或其他附属设备的损坏或丢失不承担责任。交付船只并不构成对留在船上的、非履行服务所必需的任何个人财产物品、用具或其他附属设备的寄托。\n\nc. 本协议构成双方之间就本协议标的事项达成的完整协议，并取代所有先前的协议，无论是书面的还是口头的。d. 除非由本协议各方以书面形式提出并签署，否则不得对本协议进行任何变更、修改或修订。\n\ne. 本协议中包含的所有明示陈述、保证、赔偿和责任限制在本协议因任何原因完成或终止后仍然有效。如果本协议的任何条款被具有合法管辖权的法院裁定为无效、非法或不可执行，则其余条款的有效性、合法性和可执行性绝不应因此受到影响或受损。其余条款应保持完全有效，犹如该不可执行的条款已被删除一样。双方同意以尽可能接近该被省略条款意图的有效条款替换任何被省略的条款。f. 本协议应受履行服务所在州的法律管辖并依其解释，不考虑其法律冲突原则。\n\ng. Bridgeport Boatworks 与 Owner（船东）将首先尝试通过各自代表之间的讨论来解决争议或分歧；应任何一方的要求，该等代表应在方便时尽快会面，以尝试解决此类争议或分歧。如果在会面后，代表们认定该争议或分歧无法以双方均满意的条款达成解决，双方应将争议或分歧提交不具约束力的调解。调解应由双方均同意的公正调解员主持；若双方无法达成一致，则由 American Arbitration Association（美国仲裁协会，简称“AAA”）指定的调解员主持。如果争议未能按照上述程序得以解决，除非双方另有约定，此类争议应根据当时有效的适用 AAA 规则通过仲裁进行裁决。仲裁员的裁决应为终局裁决，对双方均具有约束力，且双方无权向法院提起上诉。任何具有相应管辖权的法院均可根据适用法律就该裁决作出判决。\n通知\n\n本预估单不是发票，不代表最终应付金额或本预估单上的余额。\nCase 22-50073 Doc 728-2 Filed 08/11/22 Entered 08/11/22 14:41:45 Page 6 of 6 889-2 09/28/22 09/28/22 15:37:52\n\n本预估单不是发票，不代表最终应付金额或本预估单上的余额。\n\n如有疑问或顾虑，请致电 (860) 536-9651 联系 Bridgeport Boatworks。","key_entities":["Je","CIPA"],"ecf_references":[{"doc_number":728,"court":"CTB"}],"word_count":1919,"status":"published","published_at":"2022-08-11 00:00:00","created_at":"2022-08-11","updated_at":"2026-08-23 13:08:58"}